General Terms and Conditions - A.N. Solutions Technologies GmbH

1. General terms

The following conditions apply to all offers, sales, services and deliveries, provided, however, that no contrary agreements have been made explicitly in writing. Purchase conditions of the buyer are only applicable if they do not contradict A.N. Solutions Technologies (A.N. Solutions) General Conditions of Sale and Delivery - Export or have been accepted by A.N. Solutions in writing. All offers are without obligation. A valid contract requires a written confirmation of order issued by A.N. Solutions. Sketches, drawings and similar documentation attached to the offer are only binding A.N. Solutions if denoted as such. Goods specifically made by buyers specification may vary at delivery within 10% below or above the quantity ordered if technically unavoidable. A.N. Solutions is entitled to change the design, material and specifications even after sending their confirmation of order provided that these modifications are not contraction to the confirmation of order or buyer's specifications.

2. Terms of Payment

All invoices have to be paid in Euro or in the invoiced currency without any deductions latest within 15 days after date of invoice by remittance to our account. A.N. Solutions is entitled to request different conditions e.g. D/P, irrevocable L/C, payment in advance or the like.
Partial deliveries, which are permitted, will be invoiced separately as per the terms agreed upon for the complete order. The buyer is only entitled to set-off and lien if the counter claim is undisputed or has been declared legal. This applies only to the extend to which the goods may be reduced in value due to a fault. If the buyer is in arrears with a payment A.N. Solutions is entitled to withdraw from the contract and to invoice an adequate interest. All remaining payments are due immediately.
In the event of non-payment or late-payment, the buyer loses all warranty rights for the delivery goods.

3. Delivery dates

Delivery dates, agreed as binding or not binding, have to be fixed in writing. If binding, buyer has to furnish at the date requested by A.N. Solutions all necessary drawings, safety requirements, permits etc. In case of "Force Majored" and other unforeseeable and unusual circumstances occurring through no fault of A.N. Solutions such as overdue information from buyer, strike, lock-out etc. the delivery period is extended adequately - even if they occur with A.N. Solutions suppliers. Buyer is not entitled to any compensation in case of delay but has to be informed by A.N. Solutions as soon as possible about begin and end of such circumstances.
A delivery date counts from the date of order confirmation and is considered fulfilled when the goods have left A.N. Solutions works or when an installation has been completed. If A.N. Solutions is late in delivery through their fault buyer can only withdraw from the contract after he has set an adequate period of grace in writing which should not be shorter than four weeks. Buyer accepts partial shipments.

4. System-Setup, Installation and Services

System setup and installation efforts, putting into operation and maintenance require an additional order. The user is responsible for auxiliary secondary work including all material and complementary factors. The user has to instruct A.N. Solutions personnel about all relevant matters and safety requirements. If a delay in the above mentioned work is user's fault A.N. Solutions are entitled to invoice the costs of time of waiting and additional travels of their personnel.

5. Warranty

Unless agree otherwise the warranty period amounts basically to twelve (12) months after date of shipment. This warranty does not cover defects due to fair wear and tear, glass breakage, improper use/installation/treatment or changes/repairs of the delivery item carried out by the purchaser or a third party. Buyer's complaints have to be lodged 28 days after receipt of the goods or fulfilment at the latest. Complaints shall be accompanied by corresponding evidence e.g. quality documents, test reports, invoice etc. The warranty covers repair or replacement of the relevant items at the earliest possible date only. A.N. Solutions reserves the right to decide on the validity of the warranty claim. Claims for whole or part refunds are excluded. Defective and replaced parts become the property of A.N. Solutions. The freight charges for the parts to be replaced are borne by the customer. Any further claims due to delivery defects beyond the above warranty claims are herewith expressly excluded; in particular any liability for indirect damage sustained by the customer or a third party as a result of using a defective item is excluded.

6. Return goods

A.N. Solutions values all its customers. There is a strict returns policy to optimize customer satisfaction. In the event of any faulty or damaged goods please contact our Service Department by fax or e-mail. Please inform them upfront and they will provide you RMA-number related to your occurrence. Afterwards please return the faulty or damaged goods with our prior agreement only. We will accept all equipment back for testing (providing it is free from chemical/biological/radioactive materials or certified decontaminated/disinfected). Return the products together with the Quality Certificate, a copy of the invoice, and a note detailing the problem. Pay attention to the correct packaging and transport.

7. Jurisdiction

The law applicable to any disputes, which cannot be settled amicably, shall be that of A.N. Solutions place of business (GERMANY). However, if A.N. Solutions is plaintiff they shall also be entitled to sue before the court having jurisdiction over the buyer's place of business.

Stand: 1st September 2009

Disclaimer - General Terms & Conditions
Copyright © 2009
A.N. Solutions GmbH
Quick Find
Use keywords to find the product you are looking for.
Advanced Search
0 items
There are currently no product reviews
Parse Time: 0.085s